IDEAS home Printed from https://ideas.repec.org/a/eee/enepol/v156y2021ics0301421521002913.html
   My bibliography  Save this article

Exploring the link between project delays and cancelation rates in the U.S. rooftop solar industry

Author

Listed:
  • Cook, Jeffrey J.
  • Cruce, Jesse
  • O'Shaughnessy, Eric
  • Ardani, Kristen
  • Margolis, Robert

Abstract

About 1 in 10 rooftop solar photovoltaic (PV) customers who sign a contract to install a PV system cancel their contract before the system is installed. Although some cancelation risk is inherent in the solar industry, there may be ways to reduce cancelation volume, such as reducing project delays. Delays can occur at each stage of PV adoption processes, which take several weeks to months from contract signature to system operation. Using data from a recent survey of PV installers, we explore the factors that explain PV project delays and cancelations. The survey data suggest that PV adoptions take about 16 weeks, on average, from contract signature until system operation. Survey respondents consistently identified permitting, inspection, and interconnection (PII) processes as key drivers of project delays. Most respondents then suggested these PII-related delays increase contract cancelations. However, larger-scale installers report higher cancelation rates, and these installers rank changes in customer financial situations higher than PII-related delays as the main cause for cancelations. Most respondents also reported avoiding jurisdictions with particularly onerous PII requirements or charging more in these jurisdictions. On balance, the results provide a rationale for measures to streamline PII processes to reduce delays and potentially mitigate cancelation risk.

Suggested Citation

  • Cook, Jeffrey J. & Cruce, Jesse & O'Shaughnessy, Eric & Ardani, Kristen & Margolis, Robert, 2021. "Exploring the link between project delays and cancelation rates in the U.S. rooftop solar industry," Energy Policy, Elsevier, vol. 156(C).
    • Handle: RePEc:eee:enepol:v:156:y:2021:i:c:s0301421521002913
    DOI: 10.1016/j.enpol.2021.112421
    as

    Download full text from publisher

    File URL: http://www.sciencedirect.com/science/article/pii/S0301421521002913
    Download Restriction: Full text for ScienceDirect subscribers only
    File URL: https://libkey.io/10.1016/j.enpol.2021.112421?utm_source=ideas
    LibKey link: if access is restricted and if your library uses this service, LibKey will redirect you to where you can use your library subscription to access this item
    ---><---

    As the access to this document is restricted, you may want to search for a different version of it.

    References listed on IDEAS

    as
    1. O'Shaughnessy, Eric & Barbose, Galen & Wiser, Ryan, 2020. "Patience is a virtue: A data-driven analysis of rooftop solar PV permitting timelines in the United States," Energy Policy, Elsevier, vol. 144(C).
    2. Yanjun Liao, 2020. "Weather and the Decision to Go Solar: Evidence on Costly Cancellations," Journal of the Association of Environmental and Resource Economists, University of Chicago Press, vol. 7(1), pages 1-33.
    3. Eric T. Anderson & Karsten Hansen & Duncan Simester, 2009. "The Option Value of Returns: Theory and Empirical Evidence," Marketing Science, INFORMS, vol. 28(3), pages 405-423, 05-06.
    4. Burkhardt, Jesse & Wiser, Ryan & Darghouth, Naïm & Dong, C.G. & Huneycutt, Joshua, 2015. "Exploring the impact of permitting and local regulatory processes on residential solar prices in the United States," Energy Policy, Elsevier, vol. 78(C), pages 102-112.
    5. Hsu, Jenneille Hwai-Yuan, 2018. "Predictors for adoption of local solar approval processes and impact on residential solar installations in California cities," Energy Policy, Elsevier, vol. 117(C), pages 463-472.
    6. O'Shaughnessy, Eric & Nemet, Gregory F. & Pless, Jacquelyn & Margolis, Robert, 2019. "Addressing the soft cost challenge in U.S. small-scale solar PV system pricing," Energy Policy, Elsevier, vol. 134(C).
    7. Roman Inderst & Marco Ottaviani, 2013. "Sales Talk, Cancellation Terms and the Role of Consumer Protection," The Review of Economic Studies, Review of Economic Studies Ltd, vol. 80(3), pages 1002-1026.
    8. Dong, Changgui & Wiser, Ryan, 2013. "The impact of city-level permitting processes on residential photovoltaic installation prices and development times: An empirical analysis of solar systems in California cities," Energy Policy, Elsevier, vol. 63(C), pages 531-542.
    9. Arbora Resulaj & Roozbeh Kiani & Daniel M. Wolpert & Michael N. Shadlen, 2009. "Changes of mind in decision-making," Nature, Nature, vol. 461(7261), pages 263-266, September.
    10. Kimberly S. Wolske & Kenneth T. Gillingham & P. Wesley Schultz, 2020. "Peer influence on household energy behaviours," Nature Energy, Nature, vol. 5(3), pages 202-212, March.
    11. White, Lee V., 2019. "Increasing residential solar installations in California: Have local permitting processes historically driven differences between cities?," Energy Policy, Elsevier, vol. 124(C), pages 46-53.
    Full references (including those not matched with items on IDEAS)

    Citations

    Citations are extracted by the CitEc Project, subscribe to its RSS feed for this item.
    as


    Cited by:

    1. O'Shaughnessy, Eric & Dong, Shiyuan & Cook, Jeffrey J. & Cruce, Jesse & Ardani, Kristen & Fekete, Emily & Margolis, Robert, 2022. "Effects of local permitting and interconnection requirements on solar PV installation durations," Energy Policy, Elsevier, vol. 161(C).
    2. Kapsalis, Vasileios & Maduta, Carmen & Skandalos, Nikolaos & Wang, Meng & Bhuvad, Sushant Suresh & D'Agostino, Delia & Ma, Tao & Raj, Uday & Parker, Danny & Peng, Jinqing & Karamanis, Dimitris, 2024. "Critical assessment of large-scale rooftop photovoltaics deployment in the global urban environment," Renewable and Sustainable Energy Reviews, Elsevier, vol. 189(PB).

    Most related items

    These are the items that most often cite the same works as this one and are cited by the same works as this one.
    1. Neij, Lena & Nemet, Gregory, 2022. "Accelerating the low-carbon transition will require policy to enhance local learning," Energy Policy, Elsevier, vol. 167(C).
    2. O'Shaughnessy, Eric & Dong, Shiyuan & Cook, Jeffrey J. & Cruce, Jesse & Ardani, Kristen & Fekete, Emily & Margolis, Robert, 2022. "Effects of local permitting and interconnection requirements on solar PV installation durations," Energy Policy, Elsevier, vol. 161(C).
    3. O'Shaughnessy, Eric & Barbose, Galen & Wiser, Ryan, 2020. "Patience is a virtue: A data-driven analysis of rooftop solar PV permitting timelines in the United States," Energy Policy, Elsevier, vol. 144(C).
    4. White, Lee V., 2019. "Increasing residential solar installations in California: Have local permitting processes historically driven differences between cities?," Energy Policy, Elsevier, vol. 124(C), pages 46-53.
    5. Neij, Lena & Heiskanen, Eva & Strupeit, Lars, 2017. "The deployment of new energy technologies and the need for local learning," Energy Policy, Elsevier, vol. 101(C), pages 274-283.
    6. Kenneth Gillingham, Hao Deng, Ryan Wiser, Naim Darghouth, Gregory Nemet, Galen Barbose, Varun Rai, and Changgui Dong, 2016. "Deconstructing Solar Photovoltaic Pricing," The Energy Journal, International Association for Energy Economics, vol. 0(Number 3).
    7. Bossink, Bart, 2020. "Learning strategies in sustainable energy demonstration projects: What organizations learn from sustainable energy demonstrations," Renewable and Sustainable Energy Reviews, Elsevier, vol. 131(C).
    8. Hsu, Jenneille Hwai-Yuan, 2018. "Predictors for adoption of local solar approval processes and impact on residential solar installations in California cities," Energy Policy, Elsevier, vol. 117(C), pages 463-472.
    9. O'Shaughnessy, Eric & Grayson, Alexandra & Barbose, Galen, 2023. "The role of peer influence in rooftop solar adoption inequity in the United States," Energy Economics, Elsevier, vol. 127(PA).
    10. Wiggins, Seth, 2016. "It’s All Local? How Sub-State Policies Affect Western US Residential Solar Adoption," 2016 Annual Meeting, July 31-August 2, Boston, Massachusetts 235667, Agricultural and Applied Economics Association.
    11. Strupeit, Lars & Neij, Lena, 2017. "Cost dynamics in the deployment of photovoltaics: Insights from the German market for building-sited systems," Renewable and Sustainable Energy Reviews, Elsevier, vol. 69(C), pages 948-960.
    12. Strupeit, Lars, 2017. "An innovation system perspective on the drivers of soft cost reduction for photovoltaic deployment: The case of Germany," Renewable and Sustainable Energy Reviews, Elsevier, vol. 77(C), pages 273-286.
    13. Schwartz, Demitrius & Batabyal, Amitrajeet, 2023. "The Decision to Install a Rooftop Photovoltaic System by a Small Business: A Case Study," MPRA Paper 120361, University Library of Munich, Germany, revised 01 Mar 2024.
    14. Corbett, Charles J. & Hershfield, Hal E. & Kim, Henry & Malloy, Timothy F. & Nyblade, Benjamin & Partie, Alison, 2022. "The role of place attachment and environmental attitudes in adoption of rooftop solar," Energy Policy, Elsevier, vol. 162(C).
    15. Petrikaitė, Vaiva, 2018. "A search model of costly product returns," International Journal of Industrial Organization, Elsevier, vol. 58(C), pages 236-251.
    16. O'Shaughnessy, Eric & Nemet, Gregory F. & Pless, Jacquelyn & Margolis, Robert, 2019. "Addressing the soft cost challenge in U.S. small-scale solar PV system pricing," Energy Policy, Elsevier, vol. 134(C).
    17. Barbrook-Johnson, Peter & Tankwa, Brendon, 2023. "Increasing inequality between countries in key renewable energy costs," INET Oxford Working Papers 2023-20, Institute for New Economic Thinking at the Oxford Martin School, University of Oxford.
    18. Kapsalis, Vasileios & Maduta, Carmen & Skandalos, Nikolaos & Wang, Meng & Bhuvad, Sushant Suresh & D'Agostino, Delia & Ma, Tao & Raj, Uday & Parker, Danny & Peng, Jinqing & Karamanis, Dimitris, 2024. "Critical assessment of large-scale rooftop photovoltaics deployment in the global urban environment," Renewable and Sustainable Energy Reviews, Elsevier, vol. 189(PB).
    19. John Byrne & Job Taminiau & Kyung Nam Kim & Joohee Lee & Jeongseok Seo, 2017. "Multivariate analysis of solar city economics: impact of energy prices, policy, finance, and cost on urban photovoltaic power plant implementation," Wiley Interdisciplinary Reviews: Energy and Environment, Wiley Blackwell, vol. 6(4), July.
    20. Inderst, Roman & Tirosh, Gilad, 2015. "Refunds and returns in a vertically differentiated industry," International Journal of Industrial Organization, Elsevier, vol. 38(C), pages 44-51.

    Corrections

    All material on this site has been provided by the respective publishers and authors. You can help correct errors and omissions. When requesting a correction, please mention this item's handle: RePEc:eee:enepol:v:156:y:2021:i:c:s0301421521002913. See general information about how to correct material in RePEc.

    If you have authored this item and are not yet registered with RePEc, we encourage you to do it here. This allows to link your profile to this item. It also allows you to accept potential citations to this item that we are uncertain about.

    If CitEc recognized a bibliographic reference but did not link an item in RePEc to it, you can help with this form .

    If you know of missing items citing this one, you can help us creating those links by adding the relevant references in the same way as above, for each refering item. If you are a registered author of this item, you may also want to check the "citations" tab in your RePEc Author Service profile, as there may be some citations waiting for confirmation.

    For technical questions regarding this item, or to correct its authors, title, abstract, bibliographic or download information, contact: Catherine Liu (email available below). General contact details of provider: http://www.elsevier.com/locate/enpol .

    Please note that corrections may take a couple of weeks to filter through the various RePEc services.

    IDEAS is a RePEc service. RePEc uses bibliographic data supplied by the respective publishers.